1. Prices

All prices quoted are in Indian Rupees. All prices quoted are exclusive of all Government/Corporate, withhold, national or local tax charges.

 

 

2. Terms of Payment

Payments shall be made 50% as advance along with work order, 40% payment after completion of 50% work and 10% after full completion. Payment shall be made by bank transfer to AIPL.

 

 

3. Extended Delivery

If the contract is delayed or extended through no fault of AIPL, then we reserve the right to revise the contract price and delivery.

 

 

4. Changes and Variations

The contract price is based on the specification noted in the quotation. If the Client requests changes or variations to be made to the original scope of supply during the contract, AIPL will submit a quotation incorporating such change or variation, clearly indicating the effect on price and delivery, for acceptance by the client, before proceeding with the change or variation.

 

 

5. Procedural Events

Should AIPL agrees to work on the basis of a letter or fax of intent, AIPL Services reserves the right to suspend the work if the written order and full information enabling them to proceed are not received within 30 days from the date of the letter or telex of intent. The Client shall meet any costs involved as a result of this.

 

 

6. Cancellation

In the event of contract termination, through no fault of AIPL, the client agrees to pay AIPL for all services that have been requested and/or completed up to the cancellation date. In the event of cancellation not the fault of Contractor, Client shall be liable for any and all balances owed in full, including but not limited to fees for services rendered, reimbursable expenses, pending purchase orders as of the cancellation date, etc.

 

 

7. Working Conditions.

AIPL personnel shall not work in dangerous or unsafe conditions. If site conditions become unsafe during the progress of the site work then AIPL shall recall personnel at the cost to the client.

 

 

8. Site Facility and obligation

Local approval for project execution (i.e. local Police, Landlord, Neighbour, Municipality, local club) etc. all shall be the responsibility of client. AIPL Interior labor, mistri shall be allowed to work day, night, secure site accommodation and cooking facility. AIPL Interior if purchased material for the project from local syndicate sources then AIPL interior would not be responsible for any material quality. Power, water for sewage use and drinking water, ladder, washroom, standing Fan, shall be provided by client.AIPL services shall right to appoint Third Party Contractors and/or Installers If the Project requires the engagement of Third Party Contractors and/or Installers to perform certain technical work, Contractor is an independent contractor not an employee of client.

 

 

9. Rights and Liabilities

The rights, liabilities and obligations of the parties shall be governed by the laws of India (Central, State and Local Bodies). Client agrees that all claims arising out of or in relation to the agreement for project arrangement shall be subject to the exclusive jurisdiction of the Courts in Hyderabad.

 

 

10. License & Approvals

Client shall be responsible for obtaining and paying for all necessary licenses, and permissions for the work scope as mentioned in this price.

 

 

11. Design Copyright

Client should not share AIPL art work/high res photo/creative design without express permission from director with any third party or with any other vendor. Similar way AIPL shall not share any project design, finished project photo with other client. This is to maintain confidentially of project privacy.

 

 

12. Force Majore

AIPL shall not be liable for any failure of performance due to force majeure, an act of god, accident, fire, earth quake, Curfew, Strike, or any other event beyond its control. In this situation client agrees to pay AIPL for all services that have been requested and/or completed up to the this stage. AIPL- Arpitha Interiors Pvt. Ltd.